Legal Notice
ADVERTISEMENT FOR BIDS
CLASSROOM RENOVATIONS AT
HALE COUNTY COLLEGE AND CAREER ACADEMY
FOR THE HALE COUNTY BOARD OF EDUCATION
GREENSBORO, AL
LATHAN MCKEE – MONTGOMERY OFFICE
PROJECT NO.: 26-104
Sealed proposals for this project shall be received by Mr. Michael C. Ryans, Superintendent at the Hale County Board of Education located at 1115 Powers Street, Greensboro, AL 36744; Phone: 334-624-8836, until 2:00 PM Central Time, Tuesday, October 27, 2026, then opened and read aloud.
General Contractors bidding on this project shall be required to visit the site to examine all existing conditions prior to submitting their proposal, which shall be arranged by the contractor with the principal at the school.
All Bidders shall have general liability and workman’s compensation insurance. The project shall be bid excluding taxes. Bids must be submitted on proposal forms furnished by the Architect or copies thereof. No bid may be withdrawn after scheduled closing for receipt of bids for a period of ninety (90) days. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owners judgment, the best interests of the Owner will thereby be promoted.
A certified check or Bid Bond payable to Hale County School District in an amount not less than five percent (5%) of the amount of the bid, but in no event more than $10,000.00 must accompany the bidder’s sealed proposal. Performance and statutory labor and material payment bonds will be required at the signing of the Contract.
All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect. All bidders shall show such evidence by clearly displaying their current license number on the outside of the sealed envelope in which the proposal is delivered.
PDFs of the project can be reviewed by going to the Lathan McKee website at www.lathanmckee.com and under “Project Bid List” selecting “Montgomery”. The documents may be viewed on-line and printed by General Contractors, SubContractors and Suppliers. Documents published through this procedure are the only documents endorsed by the Architect. The Architect is unable to monitor, confirm and maintain other websites that provide documents. Notices of Addenda being posted will be provided to entities that have CONFIRMED bidding for this particular project. The Architect retains ownership and copyrights of the documents. If bidders require printed sets, please submit request to the Architect at mckeeplans@gmail.com. Include your first & last name, company name, address, phone number and the project name and number. Print sets are to be returned in reusable condition within ten days after bid opening.
All RFIs and RFAs regarding the bid documents shall be sent and addressed through emails found on the RFI and RFA forms in the project manual. NOTE: ONLY THE RFI AND RFA FORMS IN THE PROJECT MANUAL WILL BE ACCEPTED. The Architect will not accept inquiries via telephone or fax.
Completion Time: See Scope of Work in Project Manual.
Supervision: Contractor to ensure proper supervision of all work.
Owner: Mr. Michael C. Ryans, Superintendent; Hale County Board of Education; 1115 Powers Street, Greensboro, AL 36744 | Phone: 334-624-8836
Architect: Lathan McKee Architects, 3500 Eastern Blvd., Suite 300, Montgomery, Alabama 36116 | Phone: 334-834-9933
10-8-3c
Legal Notice
NOTICE OF MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF HALE
Default having been made of the terms of the loan documents secured by that certain mortgage executed by Jada Wright to Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for First Federal Bank, A FSB, its successors and assigns dated August 12, 2025; said mortgage being recorded on August 28, 2025 in Deed Book 2025, Page 413 in the Office of the Judge of Probate of Hale County, Alabama. Said Mortgage was last sold, assigned and transferred to NewRez LLC D/B/A Shellpoint Mortgage Servicing by assignment recorded in Deed Book 2026, Page 1378 in the Office of the Judge of Probate of Hale County, Alabama.
The undersigned, NewRez LLC, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Hale County, Alabama during the legal hours of sale (between 11am and 4pm), on November 25, 2026 the following property, situated in Hale County, Alabama, to-wit:
Lot 27 of The Villages Phase Two, a map or plat of which is recorded in Map Book 2, at Pages 85-85C in the Probate Office of Hale County, Alabama, reference to said map or plat being hereby made in aid of and as a part of this description.
Said property is commonly known as 169 Peyton Ln, Moundville, AL 35474.
Should a conflict arise between the property address and the legal description, the legal description will control.
Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. Bidders must perform their own due diligence. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
ATTENTION ALL PROSPECTIVE BIDDERS: On March 1, 2026, the data collection and reporting requirements under the U.S. Financial Crimes Enforcement Network (FinCEN) new Anti-Money Laundering Rule (the “Rule”), found at 89 FR 70258, went into effect. The Rule applies to certain residential real estate sale transactions (including nonjudicial foreclosures) where the transfer is to a legal entity or trust, and which includes cash purchases, private financing or financing provided by an institution not subject to a federal Anti-Money Laundering or Suspicion Activity Report requirement. As part of this Rule, purchasers and sellers are required to provide additional information and documentation about themselves, their legal entities, and the source of funds used in the reportable transaction, if applicable.* The collection of this information and documentation is required to comply with the Rule’s federal reporting requirements, if applicable. This notice is provided for informational purposes only and does not constitute legal advice. You are encouraged to consult with your own independent legal counsel if you have questions about how the FinCEN Anti-Money Laundering Rule affects your transaction and whether your transaction is reportable.
* The Rule is the subject of ongoing litigation in several jurisdictions. We suggest that you seek your own legal counsel if you have questions about the status of the Rule and its applicability to your sale, if any.
The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code, (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage, and (3) to confirmation that the successful bidder has timely provided all information required for reporting under the Rule, 89 FR 70258, if applicable.
NEWREZ LLC
as holder of said mortgage
McCalla Raymer Leibert Pierce, LLP
505 20th Street N, Suite 1775
Birmingham, AL 35203
Telephone: (205) 216-4238
FT21@mccalla.com
File No. 26-09133AL
www.foreclosurehotline.net
The Greensboro Watchman
10/15/2026,10/22/2026,10/29/2026
26-09133AL
10-15-3c
Legal Notice
IN THE CIRCUIT COURT OF HALE COUNTY, ALABAMA
CHARLES E. MYATT,
Plaintiff,
v. 36-CV-2026-900085.00
A tract or parcel of land lying in the
Southwest ¼ of the Southwest ¼ of Section
25 Township 19 North, Range 5 East, Hale
County, Alabama, Parcel Number
36-18-07-25-3-000-010.000,
and
The heirs-at-law and next-of-kin of
Adam Myatt and Nancy Hargrest and any
claimants, known or unknown of any
interest in the real property made the
subject matter of this litigation,
Defendants.
NOTICE OF CIVIL ACTION
Notice is hereby given to any Claimants or purported owners to any interest in the above-described real estate.
A civil action is pending in Hale County Circuit Court by the Plaintiff to Quiet Title in the Plaintiff of the property described as follows:
A lot or parcel of land lying and situated in the Southwest ¼ of the Southwest ¼ of Section 25, Township 19 North, Range 5 East, Hale County, Alabama, and described as beginning 580 feet South and 198 feet East of the intersection of Woods Road and the West boundary of the Southwest Quarter, and the Point of Beginning; thence South 423 feet to a point being the Southwest corner of the herein described parcel; thence East 812 feet to a point being the Southeast corner of the herein described parcel; thence North 462 feet along a branch to a point being the Northeast corner of the herein described parcel; thence West 812 feet to the Point of Beginning, and being a lot or parcel of land lying and situated in the Southwest ¼ of the Southwest ¼ of Section 25, Township 19 North, Range 5 East, Hale County, Alabama.
Hale County Parcel Number: 36-18-07-25-3-000-010.000.
Any claimants or purported owners must answer the Complaint seeking relief by the 12th day of December, 2026, or, thereafter, a judgment by default may be rendered against them in Case No. CV-2026-900085.00 Hale County Circuit Court.
DONE this, the 15th day of October, 2026.
HALE COUNTY CIRCUIT CLERK
Woodford W. Dinning, Jr.
Attorney for the Plaintiff
LLOYD & DINNING, L.L.C.
Post Office Drawer 740
Demopolis, Alabama 36732
10-22-4c
